My WebLink
|
Help
|
About
|
Sign Out
Home
Browse
Search
14 - Three-year renewal contract with Sanitation Solutions for demolition & debris removal
City-of-Paris
>
City Council
>
Agenda Packets
>
2021
>
12 - DECEMBER
>
December 13
>
14 - Three-year renewal contract with Sanitation Solutions for demolition & debris removal
Metadata
Thumbnails
Annotations
Entry Properties
Last modified
12/9/2021 3:55:27 PM
Creation date
12/9/2021 3:25:23 PM
Metadata
Fields
Template:
AGENDA
There are no annotations on this page.
Document management portal powered by Laserfiche WebLink 9 © 1998-2015
Laserfiche.
All rights reserved.
/
16
PDF
View images
View plain text
qWIU4�� <br />MUTIJOVITKI 11111111���:J ZJl:&-JVl1L&73 <br />THIS AGREEMENT is entered into this _day of2021, by <br />2nd between the City of Paris, Paris, Texas, hereinafter Galled OWNER, and <br />I with main offices located at <br />Texas; hereinafter called CONTRACTOR. <br />1.01 OWNER employs CONTRACTOR to perform and CONTRACTOR agrees to <br />perform structural demolition services in accordance with the bid form; in <br />accordance with the Master Specifications attached hereto-, and in accordance with <br />this Agreement. <br />1.02 CONTRACTOR shall complete all services under this Agreement within <br />months from the date of execution hereof. <br />1.03 OWNER agrees to provide work orders to CONTRACTOR by no later than the fifth <br />day of each month. There is no guarantee of the number of work orders which <br />will be provided; however, CONTRACTOR agrees to complete, In their entirety, no <br />fewer than five (5) outstanding work orders by no later than the last day of each <br />month. Work orders should be completed in the order in which they were given <br />to CONTRACTOR, and CONTRACTOR shall bill OWNER for completed work <br />orders in accordance with Section 1.06 hereof. <br />1.04 Additional time to perform monthly work orders will be allowed by the OWNER only <br />in the instance of substantial weather delays which make performance impractical, <br />as determined exclusively by and approved by the OWNER. Weather delays will <br />be considered by the OWNER only if requested immediately by the <br />CONTRACTOR. Because CONTRACTOR will be completing work orders based <br />on a monthly schedule, CONTRACTOR shall ensure that OWNER is made aware <br />of any and all weather delays that occur throughout the month in the event those <br />weather delays result in CONTRACTOR's failure to complete the required number <br />of work orders by the monthly deadline. <br />1.05 OWNER and CONTRACTOR recognize that time is of the essence of this Agreement and <br />that OWNER may suffer financial loss if the Work is not completed on schedule with <br />the Citys fiscal year and within the times specified above, plus any extensions thereof <br />allowed in accordance with this Agreement They also recognize the delays, <br />expense, and difficulties involved in proving in a legal or arbitration proceeding the <br />actual loss suffered by OWNER if the Work is not completed on time, Accordingly, <br />
The URL can be used to link to this page
Your browser does not support the video tag.
Print
Pages to print
Enter page numbers and/or page ranges separated by commas. For example, 1,3,5-12.
After downloading, print the document using a PDF reader (e.g. Adobe Reader).