1985-057-RES WHEREAS, the City of Paris, has need for professional services and Black & Veatch Engineers-Architects,

Home Browse Search

ARTICLE XII - Termination of Agreement by Engineer Engineer may, at any time, terminate this Agreement by giving ten (10) days' written noti ce thereof to Owner for fa i 1 u re of Owner to perform in accordance with the provisions of the Contract Documents or for failure of Owner to provide with reasonable promptness such informa- tion, decisions, fee payments or approvals as may be necessary to prevent serious disruptions or prolonged delays in the work being performed. Should Engineer terminate the Agreement Owner shall pay to Engineer all fees for direct labor costs and reimbursable expenses incurred or unalterably obligated prior to the date of Engineer's notice of termina- tion, It is specifically agreed that there shall be no claim or payment for anticipated profit. If requested, Engineer shall cooperate with Owner in orienting a new engineer with the design concepts, assumptions and work performed up to date of termination, as necessary to insure an adequate transition in engineering services and to provide continuity to project concepts, ARTICLE XIII - Additional Obligations of Engineer and Owner In addition to the obligations of Owner and Engineer SEt forth elsewhere throughout the Contract Documents, the pa rt i es hereto ackn0wledge the following additional obligations and responsibilities: Owner and Engineer acknowledge the relation of trust and confidEnce established each to the other, and each party agrees to cooperate with the other in every respect in forwarding ProjEct interests. Specifi- cally, but without limitation, Engineer covenants with Owner to furnish his best skill, care and judgment and at least the prevailing stand~rd of skill, care and judgment expected of any professional engineer under circumstances similar to those to be encountered on this Project, and to cooperate with Owner in forwarding the interests of Owner. Engineer acknowledges that Owner reserves the right by itself or through others to provide to Engineer from time to time during the Project, suggested forms and revi s ions for the Engi neeri ng Documents, Eng i neer further acknowledges that it is charged with the total professional engineering responsibility for the adequacy and sufficiency of each and every Engineering Document and for all of the Engineering Documents taken as a vlhole, which are released by Engineer as approved for construction pursuant to the Scope of Work for this Project. Additionally, Engineer acknowledges it has conducted prior analysis in developing the Project and that Owner is relying on Engineer's judgment and skill to des i gn Project to ach i eve the expected Project results as these are identified in Appendix A, PrOject Description and Scope of Work, attached hereto. 6 ~c_..._. "'..