Laserfiche WebLink
AGREEMENT <br />THIS AGREEMENT is dated as of the 14th day of May in the year 2007 by and between the <br />City of Paris (hereinafter called OWNER) and B. Bray Construction Co., Inc. (hereinafter called <br />CONTRACTOR). <br />OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, <br />agree as follow: <br />Article 1. WORK <br />CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents. <br />The Work project is generally described as follows: Construction of approximately 2025 LF 18" cavity <br />sewer, l0 fiberglass manholes, 1 concrete manhole 3 single sewer services and all misc asphalt repairs and misc <br />items on bid documents not listed. <br />Article 2. ENGINEER <br />The Project has been designed by The City of Paris Engineering Department, Paris, Texas, who <br />is hereinafter called ENGINEER and who is to act as OWNER'S representative, assume all <br />duties and responsibilities and have the rights and authority assigned to ENGINEER in the <br />Contract Documents in connection with completion of the Work in accordance with the Contract <br />Documents. <br />Article 3. CONTRACT TIME <br />3.1 The Work will be substantially completed and ready for final payment within 120 calendar <br />days from the date when the Contract Time commences to run, as provided in the General <br />Conditions. <br />3.2 Liquidated Damages. OWNER and CONTRACTOR recognize that time is of the essence of <br />this Agreement and that OWNER will suffer financial loss if the Work is not completed within <br />the times specified above, plus any extensions thereof allowed in accordance with the General <br />Conditions. They also recognize the delays, expense and difficulties involved in proving in a <br />legal or arbitration proceeding the actual loss suffered by OWNER if the Work is not completed <br />on time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR agree <br />that as liquidated damages for delay (but not as a penalty) CONTRACTOR shall pay OWNER <br />$500 for each calendar day that expires after the time specified. <br />Article 4. CONTRACT PRICE <br />OWNER shall pay CONTRACTOR for completion of the work in accordance with the Contract <br />Documents in current funds as follows: <br />At the unit prices shown on the Unit Price Bid Schedule included in the Contract Documents. <br />EXHIBIT A <br />