08-L HMAC Street Overlay Award - Laserfiche WebLink

Home Browse Search

allowances. No demand for additional payment on account of any thereof will be valid. Prior to final payment, an appropriate Change Order wifl be issued as recommended by ENGINEER to reflect actual amounts due CONTRACTOR on account of Work covered by allowances, and the Contract Price shall be correspond- ingly adjusted. Uni~ Pdce Work: 11.9.1. Where the Contract Documents provide that all or par~ of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit PHne Work an amount equal to the sum of the established unit prices for each separately identified item of Unit Price Work times the estimated quantity of each item as indi- cated in the Agreement. The estimated quantities of items of Unit Palco Work arc not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quan- tities and classifications of Unit Price Work performed by ' ' CONTRACTOR will be made by ENGINEER in accor- dance with Paragraph 11.9.2. Each unit price will be deemed to include an amount considered by CONTRAC'FOR to be adequate to cover CONTR. ACTOR's overhead and profit for each sep- arately identified item. * I 1.9.3. Where the quantity of any item of Unit Price Work performed by CONTRACTOR differs materially and significantly from the estimated quantity of such item indicated in the Agreement and there is no corresponding adjustment with respect to any other item of Work and if CONTRACTOR believes that CONTRACTOR has incurred additional expense a$a result thereof, CON- TRACTOR may make a claim for an increase in the Con- tract Price in accordance with Article I 1 if the parties are unable to agree as to the amount of any such increase. ARTICLE 12---CHANGE OF CONTRACT TIME 12.1. The Conti~ct Time may only be changed by a Change Order or a Written Amendment, Any claim for an extension or shortening of the Contract Time shall be based on written notice delivered by the party making the claim to thc other party and to ENGINEER promptly (but in no event later than thirty days) after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be deliv- ered within sixty days after such occurrence (unless ENGI- NEER allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accom- panied by the claimant's written statement that the adjust- ment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Time shall be determined by ENGINEER in accordance with para- graph 9-11 if OWN ER and CONTRACTOR cannot otherwise agree. No clair~ for an adjustmem in the Contract Time will be valid if not submitted in accordance with the requirements of this paragraph 12.1. 12.2. The Contract Time will be extended in an amount equal to time lost due to delays beyond the control o{' CON- TRACTOR if a claim is made therefor as provided in para- graph 12.1. Such delays shall include, but not be limited to, acts or neglect by OWNER or others petrol"ming additional work as contemplated by Artinle 7, or to fires, floods, labor disputes, epidemics, abnormal weather conditions or acts of God. I'L3. All time limits stated in the Contract Documents are of the essence of the Agreement. The provisions of this Article 12 shall not exclude recovery for damages (including but not limited to fees and ch_al'gas of engineers, architects, · attorneys and other professionals and court and arbitration costs) for delay by either party. ARTICLE 13--WARRANTY AND GUARANTEE; TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK Warrant~ and Guarantee: 13.1. CONTRACTOR warrants and guarantees 'to OWNER and ENGINEER that all Work will be in accor- dance with the Contract Documents and will not be defective. Prompt notice of ail defects shall be given to CONTRAC- TOR. All defective Work, whether or not in place, may be rejected, corrected or accoptcd as provided in this Article 13. Access to Work: 13.2. ENGINEER and ENGINEER's representatives, other representatives of OWNER, testing agencies and gov- ernmental agencies withjurisdictlonal interests will have access to the Work at reasonable times for their observation, in}petting and testing. CONTRACTOR shall provide proper and safe. conditions for such access. Test~ and lmpectinns: 13.3. CONTRACTOR shall give ENGINEER timely notice of readiness of thc Work for all required inspections, tests or approvals. 13.4. If Laws or Regulations of an}' public body having jurisdiction require any Work (or part thereof} to specifically be inspected, tested or approved, CONTRACTOR shall assume full responsibility therefor, pay all costs in connection therewith and furnish ENGINEER the required certificates of inspection, testing or approval. CONTRACTOR shall also *See Supplementary Conditiona