07-A Gateway Repair Project - Laserfiche WebLink

Home Browse Search

or ahcr thdr work wifl] the wl'hlen c~anscnt of ENGINEER and the olhers whose work will bc affected. Thc dut~ns and rcsponsib{lh{cs of CONTRACTO~ under this p~ragraph ~rc lo thc CXI~NI that there ~r¢ comparabfe provisions for benefit oC CONTRACTOR in said direct comrac~s between ?.3. If any pan of CONTRACTOR's Work depends for proper execution or results upon thc work of any such other contractor or utility owner (or OWNER), CONTRACTOR shall inspect and promptly report to ENGINEER in writing any delays, defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. CONTRACTOR's failure so to report win constitute an acceptance of the other ~vork as fit and proper for integra- tion with CONTRACTOR's Work except for latent or non- apparent defects and deficiencies in the other work. lures which have been utilized by ENGINEER in preparing thc Dcawings and Specifications. 8.5. OWNER's rcsponsibilitics in rcspcct-l:ff pmcimsing and maintaining liability and property insurance nrc scl forth in paragraphs .5.5 through 5.8. 8.6. OWNER is obligated t~ execute Change Orders as indicated in paragraph 10.4. 8.7. OWNER's responsibility in rcspcct of ccrtain inspections, tests and approvals is set forth in paragraph 13.4. 8.8. In connection with OWNER's right to stop Work or suspend Work, see paragraphs 13.10 and 15.1. Paragraph 15.2 deals with OWNER's right to terminate services of CON- TRACTOR under certain circumstances. ARTICLE ~ENGINEER'S STATUS DURING CONSTRUCTION Coordination: 7.4. If OWNER contracts with others for the perfor- mance of other work on the Project at the site, the person or organization who will have authority and responsibility for coordination of the activities among the various prime con- tractors will be identified in the Supplementary Conditions, and the specific matters to be covered by such authority and responsibility will be itemized, and the extent of such author- ity and responsibilities will be provided, in the Supplementary Conditions. Unless othenvise provided in the Supplementary Conditions. neither OWNER nor ENG[NEER shall have any authority or responsibility in respect of such coordination. ARTICLE g--OWNER'S RESPONSIBILITIES 8.1. OWNER shall issue all communications to CON- TRACTOR through ENGINEER. 8.2. In ca~e of tcrmlnadon of the employment of ENGI- NEER, OWNER shall appoint an engineer against whom CONTRACTOR makes no reasonable objection, whose sta- tus under the Contract Documents shall be that of the former ENGINEER. Any dispute in connection with such appoint- ment shall be subject to arbitration. 8.3. OWNER shall famish the data reqolred of OWNER under the Contract Documents promptly and shall make pay- ments to CONTRACTOR promptly alter they are due as provided in paragraphs 14.4 and 14.1~. 8.4. OWNER's duties in respect of providing lands and easements and providing coglncerlng surveys to establish reference points are set forth in paragraphs 4.1 and 4.4. Para- graph 4.2 refers to OWNER's identifying and making avail- able to CONTRACTOR copies of reports ofcxploratlons and tests of subsurface conditions at thc slte and in existing stroc- Owner's Representative: 9.1. ENGINEER will be OWNER's representative dur- ing the construction period. The duties and responsibilities and thc limitations of authority of ENGINEERas OWNER's representative during construction are set forth in the Con- tract Documents and shall not be extended without written consent of OWNER and ENGINEER. Vixlt$ to Site: 9.2. ENGINEER will make visits to the site at intervals appropriate to the various stages of construction to obser,,e the progress and quality of the executed Work and to.deter- mine, in general, if the Work is proceeding in accordance .with the Contract Decuments. ENGINEERwilt not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. ENGINEER's efforts will b¢ directed toward providing for OWNER a greater degree of confidence that thc completed Work will conform to thc Contract Documents. On thc basis of such visits and on-slte observations as an experienced and qualified design profes- slonal, ENGINEER will keep owlqER informed of the prog- ress of the Work and will endeavor to guard OWN ER against defects and deficiencies in the Work. Project Representation: * 9.3. It' OWNER and ENGINEER agree, ENGINEER will furnish a Resident Proje'~t Representative to assist ENGINEER in observing the performance of the Work. The duties, r~pon$ibil[ties and [imitations of authority of any such Resident Project Representative and assistants will be as provided in the Supplementary Conditions. If OWNER designates another agent to represent OWNER at the site who is not ENGINEER's agent or employee, the duties, rcsponsibil[tles and limitations of authority of such other per~on wdl be as prov'dcd in thc Supplementary Conditions. *See Supplementary Conditions 47