05-D Animal Shelter Contract - Laserfiche WebLink

Home Browse Search

by the Owner, the Contractor shall notiEy the Owner in writing not less than five days or other agreed period before commencing the Work to permit the timely filing of morgages, mechanic's liens and other security interests. 8.23 The Contractor shall proceed expeditiously with adequate forces and shall achieve Substantial Completion within the Contract Time. 83 DELAYS AND EXTENSIONS OF TIME 83.1 If the Comractor is delayed at any time in the commencement or progress of the Work by an act or neglect of the Owner or Architect, or of an employee of either, or of a separate contractor employed by the Owner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Contractor's control, or by delay authorized by the Owner pending mediation and arbitration, or by other causes which the Archited determines may justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Architect may determine. 83.2 Claims relating to time shall be made in accordance with applicable provisions of ParagraPh 4.3• 8.33 This Paragraph 8.3 does not preclude recovery of damages for delay b}' either party under other provisions of the Contract Documents. ARTICLE 9 PAYMENTS AND COMPLETION 9.1 CONTRAGT SUM 9.1.1 The Contract Sum is stated in the Agreement and, including authorized adjustments, is the total amount payable by the Owner to the Contractor for performance of the Work under the Contract Documents. 9.2 SCHEDULE OF VALUES 9.2.1 Before the first Applicalion For Payment, the Contractor shall submit to the Architect a schedule of values allocated to various portions of the Work, prepared in such form and supported by such data to substantiate its accuracy as the Architect may require. This schedule, unless objected to by the Architect, shatl be used as a basis for reviewing the Contractor's Applications for Payment. 93 APPLICATIONS FOR PAYMENT " 93.1 At least ten days before the date established for each progress payment, the Contractor shall submit to the Architect aa itemized Application for Payment for operations completed in accordance with the schedule of values. Such application shall be notarized, if required, and supported by such data substantiating the Contrador's right to payment as the Owner or Architect may require, such as copies of requisitions from Subcontractors and material suppliers, and reflecting retainage if provided for in the Contract Documents. 9.3.1.1 As provided in Subparagraph 7.3.8, such applications may include requests for payment on account of changes in the Work which have been properly authorized by Construction Change Directives, or by interim determinations of the Architect, but not yet included in Change Orders. 93.1.7 Such applications may not include requests for payment for portions of the Work for which the Contractor does not intend to pay to a Subcontractor or material supplier, unless such Work has been performed by others whom the Contractor intends to pay. WA0.NING: Unll<ensed photocopying vblates US. copyright laws and will subJe<f fhe violator to legal prosecution. o IIII o o. c oQ ~.~o 0 (D 199] AIAO AIA DOCUMENT A201-7997 GENERAL CONDITIONS OF THE CONTRACT FOft CONSTRUCTION The American Institute o(Architects 7735 New York Avenue, N. W. Washingfon, D.C. 20006-5292