08-L HMAC Street Overlay Award - Laserfiche WebLink

Home Browse Search

TR^CTOR shall not cndangor any work of others by cutting. c.xcovating or otherwise ahering d~cir work and will only cm or alter their work with thc written con~ot o~ ENGINEER and thc others whose work Will Be afl, clod. The duties and responsibilities of CONTRA~OR under this 9amgmph arc for thc benefit or such utitky owners and other contmcto~ to thc extent that there are comparable provisions for the beneRt of CONTRACTOR in said direct ~nt~cts between OWNER and such milhy owners and other contractors. 7.3. If any part of CONTRACTOR's Work depends for proper execution or results upon thc work of any such other contractor or utility owner (or OWNER), CONTRACTOR shall inspect and promptly report to ENGINEER in writing any delays, defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. CONTRACTOR's failure so to report will constitute an acceptance of the other work as fit and proper for integra- tion with CONTRACTOR's Work except for latent or non- apparent defects and deficiencies in the other work. tufts which hove been utilized by ENGINEER in preparing thc Drawings and Specifications. 8.5. OWblER's responsibilities in respect of pu:chaslng and maintaining liability and property insurance arc set foah in paragraphs 5.5 through 5.8. 8.6. OWNER is obligated to execute Change Orders as indicated in paragraph 10.4. 8.7. OWNER's responsibility in respect or ccrtaln inspections, tests and approvals is set forth in paragraph 13.4. 8.8. In connection with OWNER's right to stop Work or suspend Work. see paragraphs 13.10 and 15. I. Paragraph 1.5.2 deals With OWNER's right to terminate services of CON- TRACTOR under certain circumstances. ARTICLE 9--ENGINEER'S STATUS DURING CONSTRUCTION Coordination: 7.4. It' OWNER contracts wRh others t'or the perf~r2 manes or' other work on the. Project at thc site, the person or organization who (viii have authority and responsibility for coordination or' the activities among the various prime con- tractors will be identified in the Supplementary Conditions, and thc specific matters to be covered by such authority and responsibility will be itemized, and the extent of such author- ity and responsibilities will be provided.in the Supplementary Condkions. Unless other,vise provided in the Supplementary Conditions. neither OWNER nor ENGINEER shall have any authority or responsibility in respect or- such coordinatlon. ARTICLE 8~OWNER'S RESPONSIBILITIES 8.1. OWNER shall issue all communications to CON- TRACTOR through ENGINEER. 8.2. In case cf termination of the employment of ENGI- NEER. OWNER shall appoint an engineer against whom CONTRACTOR makes no reasonable objection, whose sta- tus under the Contract Documents shall be that or- the former ENGINEER. Any dispute in connection with such appoint- ment shah be subject to arbitration. 8.3. OWNER shall furnish the data required of OWNER under the Contract Documents promptly and shall make pay- merits to CONTRACTOR promptly after they are due as provided in paragraphs 14.4 and 14.13. 8.4. OWNER's dutles in respect of providing lands and easements and providing engineering surveys to establish reference points are set forth in paragraphs 4.1 and 4.4. Para- graph 4.2 refers to OWNER's identifying and making avail- able to CONTRACTOR copies of reports of explorations and tests of subsarfacc conditions at the site and in existing sitar- *See Supplementary Condicfon~ 9,1. ENGINEER will be OWNER's representative dur- ing the construction period. The dudes and responsibilities and the limitations or'authority oFENGINEERas OWNER's representatlve during construction are set forth in the Con- tract Documents and shall not be extended without xvritten consent of OWNER and ENGINEER. Vixlt$ to Site: 9.2. ENGINEER will make visits to the site at intervals appropriate to the various stages of construction to observe the progress and quality or- the executed Work and to-deter- mine, in general, if the Work is proceeding in accordance with the Co ntract Documents. ENGINEERwilI not be required to make cxhaustive or continuous on-site inspections to check the quality or quantity ot- the Work. ENGINEER's efforts will be directed toward providing for OWN ER a greater degree of confidence that the completed Work will conform to the Contract Documents. On the basis of such visits and on-site observations as an experienced and qualified design profes- slon,al, ENGINEER will keep OWNER int-ormed of the prog- ress of the Work and will endeavor to guard OWHER a~inst defects and deficiencies in the Work. Project Reprexentat~on: * 9.3. If OWNER and ENGI.NEER agree, ENGINEER will furnish a Resident Project Representative to assist ENGINEER in observing the performance of the Work. The duties, responslbEitles and limitations of authority of any such Resident Project Representative and assistants wile be as provided in the Supplementary Conditions. If OWNER designates another agent to represent OWNER at the site who is not ENGINEER's agent or employee, thc duties. responsibilities and limitations of authority of such other per, on will be as provided in the Supplementary Conditions'