06-J Cox Field Water Main - Laserfiche WebLink

Home Browse Search

allowances. No demand for additional payment ¢n account of any [haeof will be valid. Prior [o final payment, an appropriate Change Or er will be issued as recommended by ENGINEER to refl ct actual amounts due CONTRACCOR on account of Wo ( covered by allowances, and the Contract Price shall be c rrespond- ingly adjusted. Ursit Price tiYorh: 11.9.1. Where the Contract Documcnts p all or paa of the Work is to be Unit Price Wc the Contract Price will be deemed to include Price Work an amount equal to the sum of the unit prices for each separately identified item o Work times the estimated quantity of each il cated in the Agreement. The estimated quantii af Unit Price Work aze not guaranteed and at the purpose of comparison of Bids and dett initial Contract Pcice. Determinations of the s tities and classifications of Unit Price Work pe CONTRACTOR will be made by ENGINEE dance with Pa2graph 9.10. 11.9.2. Each unit price will be deemed to amaunt cansidered by CONTRACTOR [o be a coverCONTRACfOR's overhead and profit @ uately idmti6ed icem. * 11.9.3. Where the quantity of any item ol Work performed by CONTRACTOR diffen and significantly from the estimated quantity < indicated in the Agreement and there is no coadjustment wich respect to any other item of' CONTRACTOR believes that CONTRA incurred additionat expense az a result the. TRACTOR may maF:e a claim for an increase tract Price in accordance with Articie 1 I if thi unable to agree az to the amount of any such ARTICLE 12-CHANGE OF 12.1. The ConuactTime may only be changed Order or a Written Amendment. Any ciaim for ; or shonening of the Contract Time shall be base notice delivered by the party making the claim party and to ENGINEER promptty (but in no evc thirty days) afler the occurrence of the event g the claim and stating the general nature of the c of the extent o[ the claim with supporting data sl ered within sizty days after such occurrence (u NEER attows an additional period of time [o as accurate data in support of the claim) and sha panied by the claimant's written statement tha ment claimed is the entire adjus[ment to which has reason to believe it is entitled as a result of th of said event. Ail claims Cor adjustment in the C*See Supplementary Conditions. ide that initially all Unit Jnit Price n as indi- s of items solely for nining an ual quan- ormed by ' in accor- shall be determined by ENGINEER in accordance with para- graph9.11 i(OWNERandCONTRACTORcannoLotherwise agree. No claim for an adjustment in the Contract Time witl be valid if not submitted in accordance wi[h the requirements of this pacagraph 12.1. 12.2. The Contract Time will be extended in an amount equal to time lost due to delays beyond the control of CON- TRACTOR if a claim is made therefor as provided in para- graph 12.1. Such delays shall inctude, but not be limited to, acts or neglect by OWNER or others performing additional work as contemplated by Artic(e 7, or to fires, floods, labor disputes, epidemics, abnormal weather conditions or acts of God. I23. All time limits stated in the Contract Documents are of the essence of the Agreement. The provisions af this Article 12 shall not exclude recovery for damages (including but no[ limi[ed [o fees and charges of engineers, architects, attorneys and other professionals and court and arbitration costs) for delay by ei[her party. e an ART[CLE I3-WARRANTY AND GUARANTEE; :e to TESTS AND INSPEC'fIONS; sep- CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVS WORK Unit Price maceriatly such item irk and if 'OR has f, CON- [he Con- arties ace ry a Change i extension on written o the other it later than iing rise to Im. Notice ill be deliv- less ENGI- :rtain more be accom- the adjust- he claimant occurrence nlract Time Warrarsty arsd Guarantee: 13.1. CONTRACTOR warrants and guarantees to OWNER and ENGINEER that all Work witl be in accor- dance with the Contract Documents and wilt not be defective. Prompt notice of all defects shall be given to CONTRAC- TOR. All dejecrive Work,whether or not in place, may be rejected, corrected or accepted as provided in this Article 13. Aceess (o Work: 13.2. ENGINEER and ENGINEER's representatives, other representatives of OWNER, testing agencies and gov- ernmental agencies with jurisdictional interests will have access [othe Workatteasonable timesfor[heirobservation, inspec[ing and testing. CONTRACCOR shall provide proper and safe conditions for such acccss. Tests and Inspeetiorts: 133. CON'i'RAGTORshaltgiveENGINEERtimelynotice of readiness of the Work for all required inspections, tests or approvals. 13.4. If Laws or Regula[ions oC any public body having jurisdiction require any Work (or paR thereo0 to specifically be inspected, tested or approved. CONTRACTOR shalI assume Cull responsibility therefor, pay all costs in connection therewith and furnish ENGINEBR the required cerlificates oCinspection, msting or approvaL CONTRACfOR shall also S*