04-B Asbestos Abatement Bid - Laserfiche WebLink

Home Browse Search

ERI Consulting, Inc. -- defects which may develop in the other separate contractor's work after the execution of this Contractor's work. 4.3.2 Should this Contractor cause damaffe to the work or property of any separate contractor on the Project, this Contractor shall, upon due notice, endeavor to settle with such other contractor by agreement. If such separate contractor sues the Owner on account of any darmage alleged to have been so sustained, the Owner shall notify this -- Contractor who shall defend such proceedings and pay all costs in connection therewith, and if any judgment against the Owner arises therefrom, this Contractor shall pay or satisfy it. 4.3.3 This Contractor shall afford other contractors reasonable opportunity for the introduction and storage of their materials and equipment and the execution of their work and shall properly connect and coordinate his work with theirs. 4.4 COAITRACT TER14INATION: 4.4.1 Termination by Contractor. If the Work is stopped for a period of ninety (90) days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, then the Contractor may, upon ten (10) additional days written notice to the Owner and the -- Engineer/Project Manager, terminate the Contract and recover from the Owner payment for all Work executed and for any loss sustained upon -- any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages. If the Work is recommenced during the ten (10) days notice period, the Contractor may not terminate the Contract. 4.4.2 Termination by Owner. If the Contractor is adjudged as bankrupt, or if he makes a general assignment for the benefit of his creditors, or if a receiver is appointed on account of his insolvency, or if he -- persistently or repeatedly refuses or fails, except in cases for which extension of time is provided, to supply enough properly skilled workmen or proper materials, or persistently disregards laws, ordinances, rules, regulations or orders of any public authority having jurisdiction or otherwise is guilty of a substantial violation of a provision of the Contract Documents, then the Owner may, without 4/lX/03 6